Terms of Service | Revolution Contractors

1. ACCEPTANCE OF TERMS

Welcome to Revolution Contractors, LLC ("Company," "we," "us," or "our"). These Terms of Service ("Terms") govern your use of our website, online services, and digital platforms (collectively, "Services"). By accessing or using our Services, you ("User," "you," or "your") agree to be bound by these Terms and our Privacy Policy.

If you do not agree to these Terms, please do not use our Services.

2. DESCRIPTION OF SERVICES

Revolution Contractors, LLC provides:

Construction Services: General contracting, remodeling, renovation, and construction projects
Digital Platform: Project management tools, quote generation, scheduling, and communication systems
Website Services: Information sharing, project galleries, consultation requests, and customer portals
Mobile Applications: On-site project management and client communication tools

3. ELIGIBILITY AND REGISTRATION

User Requirements

To use our Services, you must:

Be at least 18 years of age
Have the legal authority to enter into binding agreements
Provide accurate and complete registration information
Maintain the security of your account credentials

Account Registration

You may need to create an account to access certain features
You are responsible for all activity under your account
You must notify us immediately of any unauthorized use
We reserve the right to suspend or terminate accounts for violations

4. ACCEPTABLE USE

Permitted Uses

You may use our Services to:

Request quotes and consultations for construction projects
Communicate with our team about ongoing projects
Access project updates and documentation
Browse our portfolio and service information
Schedule appointments and site visits

Prohibited Uses

You may NOT:

Use our Services for any unlawful purpose
Impersonate any person or entity
Upload malicious code, viruses, or harmful content
Attempt to gain unauthorized access to our systems
Interfere with or disrupt our Services
Harvest or collect user information without consent
Use automated systems without our written permission
Violate any applicable laws or regulations
Post false, misleading, or defamatory content
Infringe on intellectual property rights

5. USER CONTENT

Content You Provide

You may submit various content including:

Project specifications and requirements
Photos and property information
Messages and communications
Reviews and feedback
Account profile information

Your Responsibilities

By submitting content, you represent that:

You own or have rights to the content
The content is accurate and not misleading
The content does not violate any laws or third-party rights
You have necessary permissions for property photos and information

License to Company

You grant us a non-exclusive, royalty-free license to use, display, and reproduce your content solely for:

Providing our construction services
Creating quotes and project documentation
Communicating about your project
Improving our Services (with personal information removed)

6. CONTRACTING SERVICES

Service Agreements

Construction work requires separate written contracts
These Terms do not constitute a construction contract
All project specifications, timelines, and pricing are subject to formal agreements
Work begins only after signed contracts and required permits

Estimates and Quotes

Online estimates are preliminary and subject to on-site verification
Final pricing may vary based on actual conditions and requirements
Quotes are valid for 30 days unless otherwise specified
Additional costs may apply for scope changes or unforeseen conditions

Project Communication

We provide digital tools for project updates and communication
Important decisions require written confirmation
You are responsible for timely responses to project-related communications
Change orders must be approved in writing

7. PAYMENT TERMS

Website Services

Basic website access is provided at no charge
Premium features may require paid subscriptions
Payment processing is handled by secure third-party providers
All fees are non-refundable unless otherwise stated

Construction Services

Payment terms are specified in individual project contracts
We accept various payment methods as outlined in contracts
Late payments may incur additional fees
Liens may be filed for non-payment as permitted by law

8. INTELLECTUAL PROPERTY

Company Property

All content, trademarks, logos, software, and intellectual property on our Services remain our exclusive property or that of our licensors.

Limited License

We grant you a limited, non-exclusive license to access and use our Services for their intended purpose. This license does not include:

Commercial use of our content
Modification or derivative works
Distribution or public display
Removal of proprietary notices

9. PRIVACY AND DATA PROTECTION

Your privacy is important to us. Please review our Privacy Policy, which explains how we collect, use, and protect your information. By using our Services, you consent to our data practices as described in the Privacy Policy.

10. DISCLAIMERS AND WARRANTIES

Service Availability

We strive for continuous service availability but cannot guarantee uninterrupted access
Services may be temporarily unavailable for maintenance or updates
We are not responsible for internet connectivity issues

Information Accuracy

We make reasonable efforts to provide accurate information
Construction information is subject to local codes and regulations
You should verify all information with relevant authorities
Professional advice should be sought for specific situations

Third-Party Content

Our Services may contain links to third-party websites or services
We are not responsible for third-party content or practices
Third-party services have their own terms and privacy policies

11. LIMITATION OF LIABILITY

TO THE MAXIMUM EXTENT PERMITTED BY LAW:

Excluded Damages

WE ARE NOT LIABLE FOR:

Indirect, incidental, or consequential damages
Loss of profits, data, or business opportunities
Damages from service interruptions or delays
Third-party actions or content
Force majeure events

Damage Cap

Our total liability to you shall not exceed the greater of:

$100
The amount you paid for Services in the 12 months prior to the claim

Construction Projects

Liability for construction services is governed by separate project contracts and is not limited by these Terms.

12. INDEMNIFICATION

You agree to indemnify and hold harmless Revolution Contractors, LLC, its employees, and agents from any claims, damages, or expenses arising from:

Your use of our Services
Your violation of these Terms
Your content or submissions
Your violation of third-party rights
Any negligent or wrongful conduct

13. TERMINATION

Termination by You

You may stop using our Services at any time
Account closure does not affect existing construction contracts

Termination by Us

We may suspend or terminate your access for:

Violation of these Terms
Fraudulent or illegal activity
Non-payment of fees
Abusive behavior toward our staff

Effect of Termination

Upon termination:

Your right to use our Services ends immediately
We may delete your account and associated data
Outstanding obligations survive termination
Construction contracts remain in effect per their terms

14. DISPUTE RESOLUTION

Informal Resolution

Before formal proceedings, we encourage direct communication to resolve disputes.

Binding Arbitration

Disputes shall be resolved through binding arbitration administered by the American Arbitration Association under its Commercial Arbitration Rules. The arbitration shall take place in Pinellas County, Florida.

Exceptions

The following are excluded from arbitration:

Small claims court matters
Injunctive relief requests
Intellectual property disputes
Construction lien proceedings

15. GENERAL PROVISIONS

Governing Law

These Terms are governed by the laws of Florida without regard to conflict of law principles.

Severability

If any provision is found unenforceable, the remaining provisions remain in full force and effect.

Entire Agreement

These Terms, together with our Privacy Policy and EULA, constitute the entire agreement regarding use of our Services.

Updates and Modifications

We may update these Terms at any time. Material changes will be communicated through:

Website notifications
Email to registered users
In-app notifications

Continued use after changes constitutes acceptance of updated Terms.

Assignment

We may assign these Terms without notice. You may not assign your rights or obligations without our written consent.

Waiver

Our failure to enforce any provision does not constitute a waiver of our rights.

16. FORCE MAJEURE

We are not liable for delays or failures due to circumstances beyond our reasonable control, including:

Natural disasters
Government actions
Labor disputes
Internet service disruptions
Supplier failures

17. NOTICES

Legal notices should be sent to:

Revolution Contractors, LLC
Legal Department
701 37th St S
St. Petersburg, FL 33711
Email: info@revolutionfl.com

Notices to you will be sent to the email address associated with your account.

18. CONTACT INFORMATION

For questions about these Terms of Service:

Revolution Contractors, LLC
701 37th St S
St. Petersburg, FL 33711
Phone: (727) 888-6161
Email: info@revolutionfl.com
Website: revolutionflorida.com

By using our Services, you acknowledge that you have read, understood, and agree to be bound by these Terms of Service.

Effective Date: August 6, 2025